A dispute pending in the Armed Services Board of Contract Appeals (ASBCA) dealt with interesting legal issues on a motion to dismiss. See Appeals of McCarthy Hitt-Next NGA West JV, ASBCA No. 63571, 2023 WL 9179193 (ASBCA 2023). The dispute involves a contractor passing through subcontractor claims due to impacts caused by the COVID-19 pandemic and the government’s response to the pandemic. More particularly, the claim centers on the premise that the government “failed to work with [the contractor] in good faith to develop a collaborative and cooperative approach to manage and mitigate the impacts and delays arising from the COVID-19 pandemic.” See Appeals of McCarthy Hitt.

The contractor (again, submitting pass through claims from subcontractors) claimed: (a) constructive changes to the contract entitling it to an equitable adjustment under the Changes clause of Federal Acquisition Regulation (F.A.R.) 52.243-4; (b) construction suspensions of the contractor’s work entitling it to an equitable adjustment under the Suspensions of Work clause of F.A.R. 52-242-14; and (c) the government breached the implied covenant of good faith and fair dealing. Each of these legal issues and theories will be discussed below because they are need-to-know legal issues. Keep these legal issues in mind, and the ASBCA’s ruling on the motion to dismiss as its analysis may demonstrate fruitful in other applications.